Term Conditions – Emerson Technology

Terms and Conditions

Acceptance of Terms
By engaging with Emerson Technology for IT services, you agree to be bound by these Terms and Conditions. This agreement outlines your rights, obligations, and the terms under which we provide our services. If you disagree with any part of these terms, please refrain from using our services.
Definitions

Services: Includes IT Consulting, Web Applications, Software Development, UI/UX Design, Hybrid Mobile Apps, and IT Staff Augmentation.
Client: The individual or organization utilizing our services.
Company: Refers to Emerson Technology.

Scope of Services
We offer a variety of IT services as agreed upon in your project contract:

IT Consulting: Advice and strategy planning to optimize your technology systems.
Web Applications: Design and development of customized web solutions.
Software Development: Building tailored software to meet specific business requirements.
UI/UX Design: Creating intuitive, user-friendly interfaces.
Hybrid Mobile Apps: Development of cross-platform mobile applications.
IT Staff Augmentation: Providing skilled professionals to supplement your existing team.

Each service will be delivered as per the project’s scope, timeline, and requirements outlined in our agreement.

Client Responsibilities
To ensure the success of our collaboration, the client agrees to:

Provide accurate and complete project requirements.
Respond promptly to requests for information or approvals.
Ensure access to any systems, tools, or environments needed to perform the services.
Maintain clear communication throughout the project lifecycle.

Invoices and Payment: All payments are due upon receipt unless otherwise specified in the contract.
Late Payments: A late fee of 2% may apply for overdue invoices.
Milestone Payments: For larger projects, payments may be broken down into milestones as outlined in your contract.
Refund Policy: Refunds, if applicable, will be subject to the terms of the specific agreement and the stage of project completion.

Project Timelines and Delivery
We commit to delivering services within the agreed timelines. However, timelines are subject to:

Timely client responses and approvals.
Unforeseen technical or resource challenges.
Delays due to client-side issues will not be the responsibility of Emerson Technology.

Revisions: Revisions are included as outlined in your contract. Additional revisions beyond this scope may incur extra charges.
Change Requests: Any requests for changes to the project’s scope, functionality, or timeline must be communicated in writing and may result in additional costs or time extensions.

Ownership: Upon full payment, the client will own the deliverables created specifically for their project.
Licenses: Emerson Technology retains the right to use non-proprietary components, frameworks, or tools developed during the project in future works.
Third-Party Tools: Any third-party software or tools integrated into your solution will be subject to their respective licensing agreements.

Confidentiality
Both parties agree to keep all sensitive information, such as business strategies, technical data, and client information, confidential.

Client Data: Your data will not be shared or used for purposes beyond the agreed project.
Non-Disclosure: A mutual non-disclosure agreement (NDA) may be signed to formalize confidentiality commitments.

Indirect or consequential damages, including loss of profit or data.
Delays or failures due to circumstances beyond our control (e.g., natural disasters, third-party outages).
Any client-side misconfigurations, misuse, or failure to follow provided guidelines.
Our liability is limited to the amount paid for the services in question.

Warranties and Disclaimers
We provide services “as is” and make no guarantees regarding:

Specific outcomes or business results.
Compatibility with third-party systems unless explicitly stated.
We commit to delivering services with professional care and in accordance with industry standards.

Termination of Agreement
Either party may terminate the agreement under the following conditions:

By Client: Termination requests must be submitted in writing, with any outstanding payments settled.
By Company: We may terminate services if the client violates these terms or fails to meet payment obligations.
Upon termination, access to deliverables or services may be revoked.

Governing Law and Dispute Resolution
These Terms and Conditions are governed by the applicable laws of the United Kingdom. We ensure compliance with international regulations, such as GDPR, CCPA, or other relevant data protection laws depending on your location.

Dispute Resolution: Any disputes will first be attempted to resolve through good faith negotiations. If unresolved, disputes may be escalated to binding arbitration or legal proceedings in a mutually agreed jurisdiction.

Amendments
We reserve the right to modify these Terms and Conditions at any time. Clients will be notified of any changes via email or updates on our website. Continued use of our services after changes are posted constitutes your acceptance of the revised terms.
Contact Information
For any questions regarding these Terms and Conditions, please contact us: